This RFQ is specific to the qualification of Respondents for Segments A1/2 and B1/2. The WHCRWA released an RFQ for construction services for Segments A, B, and C (excluding Segment B3) in March 2019 (the “Original RFQ”) and qualified nine (9) Respondents in June 2019 based on the SOQs received. Segment C is currently under construction, but there have been delays with advertising Segments A1/2 and B1/2 for construction. Due to the amount of time that has transpired, the WHCRWA has elected to solicit responses from additional respondents for the Segments A1/2 and B1/2 projects.

Qualifications, addressed to West Harris County Regional Water Authority, will only be received electronically using the “E Bidding” function on the CivcastUSA website (www.CivcastUSA.com) until 2:00 PM, Local Time, April 21, 2021 for “Request for Qualifications for Construction Services-Surface Water Supply Project- Segments A1/2 and B1/2 for the West Harris County Regional Water Authority (WHCRWA), Harris County, Texas.” SOQs received after the closing time will be rejected. Respondents must register on the CivcastUSA website in order to submit Statement of Qualifications (SOQs). Visit the CivcastUSA summary page by clicking here for more information.

Segment B (B1, B2, B3)

Approximately 14.8 miles of 96-inch diameter pipeline.

B1 – Brittmoore Road to White Oak Bayou

  • Pipeline Diameter: 96″
  • 5.8 Miles long

Anticipated Construction Program Schedule

DESIGN

Fall 2020

BID

Spring – Summer 2021

CONSTRUCTION

Fall 2021

Design Consultant: Black & Veatch

Contractor: (To be posted)

PDF Map: SWSP – Segment B1

Contractor Notice to Proceed: (To be posted)

Project Completion: (To be posted)

Dates are subject to change

SWSP - Segment B1

B2 – White Oak Bayou to IH-45W

  • Pipeline Diameter: 96″
  • 4.6 Miles long

Anticipated Construction Program Schedule

DESIGN

Fall 2020

BID

Spring – Summer 2021

CONSTRUCTION

Fall 2021

Design Consultant: Black & Veatch

Contractor: (To be posted)

PDF Map: SWSP – Segment B2

Contractor Notice to Proceed: (To be posted)

Project Completion: (To be posted)

Dates are subject to change

SWSP - Segment B2

B3 – West of IH-45 to Hopper Road (Long Tunnel)

  • Pipeline Diameter: 96″
  • 4.4 Miles long

Qualified Contractors

The Board reviewed the submittals for Construction of the Segment B3 Long tunnel. Black & Veatch and Dannenbaum provided recommendations. Nine submittals were received, and seven of the nine were determined to meet the minimum qualifications detailed in the RFQ. The list below is the Prequalified firms for the B3 Construction.

  1. Granite Construction Company
  2. JAY-DEE Contractors, Inc.
  3. McNally Tunneling Corporation/Kiewit JV
  4. Michels Corporation
  5. SAK Construction, LLC
  6. Super Excavators, Inc.
  7. Triad Engineering & Contracting Co. – TMM JV

Anticipated Construction Program Schedule

DESIGN

Fall 2020

BID

Spring – Summer 2021

CONSTRUCTION

Fall 2021

Design Consultant: Black & Veatch

Contractor: (To be determined)

PDF Map: SWSP – Segment B3

Contractor Notice to Proceed: (To be determined)

Project Completion: (To be determined)

Dates are subject to change

SWSP - Segment B3